Chefalo Contracting

Menu
Terms & Conditions – Chefalo Contracting

Terms & Conditions

Effective Date: July 10, 2025

These Terms & Conditions (“Terms”) govern your use of the website https://chefalocontracting.com and any services offered by Chefalo Contracting LLC (“Company”, “we”, “our”, “us”). By accessing or using our site or services, you agree to these Terms.

Services Offered

Chefalo Contracting provides home renovation and improvement services including but not limited to: additions, attic renovations, kitchen and bathroom remodeling, fire & water restoration, roofing, new constructions, outdoor builds, solar installations, repairs, maintenance, and general contracting across New York and select counties in Western Connecticut.

Quotes, Payments & Billing

  • All pricing is valid only for the items listed in the estimate. Additional work not listed will be billed separately.
  • Payment Schedule:
    • 25% due at project start
    • 25% due at 25% completion
    • 25% due at 50% completion
    • 12.5% due at 75% completion
    • Final 12.5% due on day of completion
  • A 12% late fee will be applied every 30 days on unpaid balances.
  • Financing options may be available through partnered third-party providers.

Warranties & Refunds

We honor all manufacturer warranties on materials used. Labor warranties may vary per project and will be discussed in your contract. Refunds are not provided unless explicitly stated in the project agreement.

Scheduling & Consultations

Customers may request a free consultation or quote via our website. Scheduling of work and formal agreements are handled directly with the contractor and subject to availability.

Project Delays & Rescheduling

We make every effort to meet project deadlines. However, delays due to weather, material availability, or client-side readiness may result in rescheduling. We are not liable for such delays and reserve the right to adjust timelines accordingly.

Insurance & Liability

Chefalo Contracting is fully insured with general liability, workers’ compensation, and disability coverage. If accidental damage occurs on-site, our insurance provider will assess and determine responsibility. We are not responsible for any damage or loss caused by factors outside our control, including acts of nature, material delays, or customer inaction.

Third-Party Contractors

We may use licensed subcontractors or third-party service providers to complete parts of your project. All such parties are vetted and expected to meet our quality and safety standards.

Licensing

All services are performed under licensed contractors authorized to operate in the State of New York.

Dispute Resolution

If any disagreement arises related to our work or services, both parties agree to attempt resolution through mediation before pursuing legal action. If mediation fails, legal claims must be filed in a New York state court of competent jurisdiction.

Limitation of Liability

We are not liable for indirect, incidental, or consequential damages arising from the use of our services. We also disclaim responsibility for issues beyond our control, including power outages, delivery disruptions, severe weather, labor shortages, or supply chain delays.

Website Use

You may not use our website for any unlawful or abusive purposes. We reserve the right to restrict or terminate access to anyone misusing the site, forms, or communication tools.

Copyright & Intellectual Property

All content on this website—including but not limited to text, images, graphics, project photos, logos, branding elements, layout, and design—is the exclusive property of Chefalo Contracting LLC, unless otherwise stated. This includes images of past work, renovations, or projects displayed on our website.

Any unauthorized reproduction, redistribution, or use of our content—whether for commercial or personal purposes—is strictly prohibited and may result in legal action. You may not copy, download, or screenshot our job site images, before/after transformations, or company logo without express written permission.

By submitting a review, testimonial, or feedback through our website, email, social media, or any third-party platform (e.g., Google, Yelp, Facebook), you grant Chefalo Contracting LLC a perpetual, royalty-free, worldwide license to use, reproduce, publish, and display that content for marketing, advertising, and promotional purposes. This includes the right to edit for clarity or length.

We are not obligated to provide compensation, credit, or seek further approval for using submitted feedback.

Changes to These Terms

We may update these Terms at any time without prior notice. The latest version will always be posted on this page. Continued use of our site or services after changes are made means you accept the updated Terms.

Contact Us

If you have any questions about these Terms & Conditions, contact: